Bhawan Nirman Agreement
I need a contract document between the contractor and the building owner before I start in the Bengali language. I am the owner of the building, I need the agreement between me and the person I should do the work for him. 11. In the event of a dispute or difference between the parties, whether with respect to the quality of the equipment or the work provided by the contractors, or because of the delay in the completion of the work or in the payment of additional work to be carried out and performed, or with respect to the measurement of the work done or the late payment with respect to the contractors or with regard to the : , compliance with any of the conditions of these gifts or any other matter that arises from or in connection with these gifts or the performance of the work, is referred to arbitration by two arbitrators, one appointed by each party. Referees appoint an arbitrator before entering the reference. Arbitrators make their arbitration awards within six months of the date the reference is seized. If the arbitrators have not delivered their sentence within the time limit or have not communicated in writing to a party or arbitrator a notification in which they declare in writing that they cannot give their consent, the arbitrator immediately takes the reference and makes his award within three months from the date of approval or within the time limit set by the parties. and, in the absence of such an agreement, which the Court of Justice may authorize. Arbitrators or arbitrators are entitled to review the costs incurred by the parties, after prior notification to the parties. The referees` procedure must be noted in English and a copy of it must be forwarded to each party.
This reference to arbitration is governed by the provisions of the Arbitration and Conciliation Act of 1996, to the extent that they are applicable and not inconsistent or contrary to these gifts. The cost of the reference and the award is left to the discretion of the arbitrators, who can direct the same or part of it by whom and in what way. The arbitral award of the arbitrator or arbitrator is final and binding for the parties and the parties, their enforcers and directors must obey each other in their respective manners, stick to arbitration and not reveal themselves for any reason, except for the fraud or collusion or error that manifests itself on the face of the award. It is heresyly agreed between the parties that the parties resort to arbitration before they file an appeal to enforce the law of these gifts. I need a contract form before I start my building in Bengali language. I am very pleased with this agreement, but I would be very helpful if Schedule II, which is mentioned in point 2, was also provided with understanding and support. Because it is difficult to fix payments and associated delivery services. 3. If the owners do not complete this work within the time frame set out in the above provision, the owners pay on the owner`s choice, but without prejudice to the other legal rights of the owner and other provisions of the owner, damages liquidated to the tune of Rs………. per day (but subject to a ceiling of 2% of the total amount of the contract payable by the owner under this agreement) for the period between the specified period for completion of the work. The owners expressly agree and authorize the owner to deduct, if necessary, from such liquidated damages from a staggered payment due and to pay to the owners within the meaning of this agreement.
11. Any dispute or dispute concerning specifications, constructions, drawings and the quality of the treatment or equipment used in the work or any other issue raised by or in connection with the contract, design, drawings, specifications, specifications or any other form related to the agreement or execution of the work, the arbitration procedure of two arbitrators is referred to the exclusive arbitration of two arbitrators during the course of the or after completion or task. , one of each